Clause

52.211-11 Liquidated Damages-Supplies, Services, or Research and Development.

(a) If the Contractor fails to deliver the supplies or perform the services within the time specified in this contract, the Contractor shall, in place of actual damages, pay to the Government liquidated damages of $__ per calendar day of delay [Contracting Officer insert amount].

Type: Clause (C)
Prescribed in: 11.503(a)
Effective: Sept 2000
Primary source: eCFR 48 CFR 52.211-11 · acquisition.gov

Text excerpt from the eCFR API; read the full clause at the eCFR link above.

Applicability in the matrix

Contract types for 52.211-11 as published in the Smart Matrix
IBR	Yes Incorporated by reference
UCF	I
FP SUP	O Optional
FP R&D	O Optional
FP SVC	O Optional
LMV	O Optional
SAP	O Optional
UTL SVC	O Optional

Reporting, not advice

MyFCExperts reports what the official federal clause matrix says applies at a given contract type, and what each clause says and where it is prescribed. It does not determine whether a specific contract or subcontract is compliant, and nothing here is legal advice or creates an attorney-client relationship. Always read the linked primary source and consult a qualified professional for your own situation.

Follow the clause matrix without re-reading it

The clause reference is free to browse. The MyFCExperts Clause Access membership adds saved contract profiles and the nightly clause-change feed for the contract types you pin. (The full clause matrix and flow-down views stay free.).

Join for $129 one-time Create a free account