Clause

52.211-12 Liquidated Damages-Construction.

(a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor shall pay liquidated damages to the Government in the amount of __ [Contracting Officer insert amount] for each calendar day of delay until the work is completed or accepted.

Type: Clause (C)
Prescribed in: 11.503(b)
Effective: Sept 2000
Primary source: eCFR 48 CFR 52.211-12 · acquisition.gov

Text excerpt from the eCFR API; read the full clause at the eCFR link above.

Applicability in the matrix

Contract types for 52.211-12 as published in the Smart Matrix
IBR	Yes Incorporated by reference
UCF	F
FP CON	O Optional
CR CON	O Optional
SAP	O Optional

Reporting, not advice

MyFCExperts reports what the official federal clause matrix says applies at a given contract type, and what each clause says and where it is prescribed. It does not determine whether a specific contract or subcontract is compliant, and nothing here is legal advice or creates an attorney-client relationship. Always read the linked primary source and consult a qualified professional for your own situation.

Follow the clause matrix without re-reading it

The clause reference is free to browse. The MyFCExperts Clause Access membership adds saved contract profiles and the nightly clause-change feed for the contract types you pin. (The full clause matrix and flow-down views stay free.).

Join for $129 one-time Create a free account